!['ABSTRACT OF LETTERS FROM INDIA 1870' [‎52v] (111/798)](https://iiif.qdl.qa/iiif/images/81055/vdc_100000000912.0x0000db/IOR_L_PS_20_CA10_0111.jp2/full/!1200,1200/0/default.jpg "'ABSTRACT OF LETTERS FROM INDIA 1870' [‎52v] (111/798)")
'ABSTRACT OF LETTERS FROM INDIA 1870' [52v] (111/798)
The record is made up of 1 volume (395 folios). It was created in Dec 1869-Dec 1870. It was written in English. The original is part of the British Library: India Office The department of the British Government to which the Government of India reported between 1858 and 1947. The successor to the Court of Directors. Records and Private Papers Documents collected in a private capacity. .
Transcription
This transcription is created automatically. It may contain errors.
from which it will he seen that the allegations of Mr. Bray’s agent are
incorrect. It is true that he was told not to take more rails from the
Koolburgah stores till the wants of the section from Sholapoor to
Koolburgah had been met; but he had at that time four miles of rails
in his possession in excess of what had been laid on the road, and
although the prohibition against the removal of rails from the stores
has been withdrawn since 27th October last, not more than a mile of
them have been taken away by the contractor.
The only work to which the complaint of want of plans can apply
is the Shahabad viaduct. The original design could not be carried
out by the contractor for want of a sufficient supply of timber and of
pumps. The true explanation of the delay in completing the bridges
beyond Koolburgah has been want of proper plant for getting in wet
and deep foundations.
You are aware that we were strongly opposed to giving Mr. Bray
any rates in excess of those on which he had agreed to carry out his
contract. We apprehended from past experience that these conces
sions, besides being wrong in principle, tended to retard, instead of to
promote, the completion of the railway. Our fears have proved true
as regards this contract. The Company wished to open as far as
Shahabad, or the first 16 miles of the contract, at the same date as
they opened to Koolburgah; and to enable them to do this, they pro
posed to lay in diversions at the two unfinished bridges. The con
tractor would have been a gainer to some extent by consenting to the
arrangement. He would have had the use of the diversions in carrying
forward his materials, and he would have been entitled to maintenance
for keeping his banks in order. But his agent declined to permit the
Company to run over any portion of the line included in the contract
before the date to which the period of completing the whole contract
had been extended, unless the Company agreed to pay some demands
he made, amounting to about 5^
lacs
One lakh is equal to one hundred thousand rupees
, for increased rates, compen
sation, Sec. Our Consulting Engineer states that some of the claims
put forward are frivolous, and that none of them are, in his opinion,
tenable in a Court of Law. He further states that the feeling
engendered between the Engineers and contractors by the difficulties
raised, and the unfounded complaints made by the agent, has had a
most injurious effect on the progress of the works, and he fears that
this season will be wasted, unless measures are taken to put an end to
the present most unsatisfactory management of affairs. We have
directed the Agent of the Company to take what legal steps may be in
his power to secure the prosecution of the works, and to give notice that
the time for the completion will not be extended on any plea beyond
the 30th June next. Mr. Bray’s agent admits that the work can be
finished by that time, but at the same time he points out that the
energetic prosecution of the works, which this rate of progress will
render necessary, would involve him in greater expense than if he
About this item
- Content
Confidential printed abstracts of letters received by the India Office The department of the British Government to which the Government of India reported between 1858 and 1947. The successor to the Court of Directors. from the Government of India, and from senior officials in certain areas outside India, during the year 1870. The letters are dated December 1869-December 1870. The abstracts each have one of the following titles:
- Abstracts of Secret Letters received from India
- Abstracts of Letters received from India
- Abstracts of Military Letters received from India
- Abstracts of Letters received from Zanzibar and Muscat
- Abstracts of Letters received from Aden
- Abstracts of Letters received from Muscat
- Abstracts of Letters received from Bushire [Bushehr]
- Abstracts of Letters received from Aden and Zanzibar
- Abstracts of Letters received from Bushire and Aden
- Abstracts of Letters received from Zanzibar and Aden.
Each abstract contains summaries of one or more letters from the specified source, each with a title giving the subject of the letter. Letters from India are divided within each abstract by the branch or department of the Government of India they originated from. The correspondence covers issues including:
- Pay, pensions, recruitment, and other personnel issues in the Indian Civil and Military establishments
- Public works, including: railways, including a proposed railway from the Mediterranean to the Persian Gulf The historical term used to describe the body of water between the Arabian Peninsula and Iran. ; roads; canals; irrigation; docks; and river embankments
- Revenue, expenditure, and taxation
- Land issues, including: the cultivation of cotton, cinchona, and silk; forestry; and coal mining
- Education
- Banking
- Telegraphy, including international telegraphic links to India
- Affairs concerning Princely States, including internal administration, debts, allowances, issues of succession, investment in railways, and territorial claims
- Issues around emigration from India to British and French colonies
- Legislative and judicial affairs, including the question of jurisdiction over British subjects in the Persian Gulf The historical term used to describe the body of water between the Arabian Peninsula and Iran.
- Military affairs, including the organisation and supply of military units and a proposed naval force for the Indian seas and the Persian Gulf The historical term used to describe the body of water between the Arabian Peninsula and Iran.
- Frontier affairs: relations with tribes on the Northwest and Northeast Frontiers and frontier raids
- Affairs in Persia [Iran], including: Persian claims to sovereignty over Bahrein [Bahrain] and objection to British actions in Bahrein; frontier disputes around Khelat [Kalat], Mekran [Makran], and Seistan [Sistan] and proposed arbitration of the Persian-Afghan border; anticipated food shortages and subsequent disturbances involving British subjects exporting grain from Bushire
- Affairs in the Sultanate of Muscat and Oman, including: the consolidation of and challenges to the rule of Syud Azan [Azzān bin Qays Āl Bū Sa‘īd]; debates around British policy towards Syud Azan; confrontation between Muscat and the Wahabees [Waḥabī movement]; the issue of the Zanzibar subsidy; and Syud Azan’s claims to Bunder Abbas [Bandar-e ‘Abbas], Gwadur [Gwadar], Charbar [Chabahar] and other territories on the Mekran Coast
- Affairs in the Persian Gulf The historical term used to describe the body of water between the Arabian Peninsula and Iran. , including: the campaign of Colonel Lewis Pelly in Bahrein and the installation of Esau bin Ali [‘Īsá bin ‘Alī Āl Khalīfah] as Ruler; trade and shipping in the Gulf; the desire of the Shah of Persia for a naval presence in the Gulf; Dutch and Turkish [Ottoman] activity in the region; and tensions between Bahrein and the Wahabees, including Wahabee inroads in the Guttur peninsula [Qatar]
- Affairs in Affghanistan [Afghanistan], including relations with Bokhara [Emirate of Bukhara] and Russia
- Central Asian affairs, including the Russian advance in the region, trade and communication from India to Central Asia via Cashmere [Kashmir] and Ladak [Ladakh], and affairs in Eastern Turkestan [Xinjiang]
- Affairs in Zanzibar, including the slave trade, relations with Muscat, the death of Syud Majid [Mājid bin Sa‘īd Āl Bū Sa‘īd], and the accession to the throne of Syud Burgash [Barghash bin Sa‘īd Āl Bū Sa‘īd]
- Affairs in and around Aden Settlement, including: relations with neighbouring polities, including Lahej [Laḥij Sultanate], Houshebi [Ḥawshabī Sultanate], Fodtheli [Faḍlī Sultanate], and Kathiree [Kathīrī Sultanate]; the purchase of Little Aden; the defences of Aden; an attack on Hodeida [Al Hudaydah] from Aseer [‘Asir] and the threat to Lahej from the Zaidees [Zaidīs]
- Affairs in the Red Sea, including attempted French, Austrian, Turkish, and Egyptian inroads in the region
- Affairs in Burmah [Burma/Myanmar], Bhootan [Bhutan], and Nipal [Nepal].
The primary correspondents are:
- The Government of India
- The Viceroy and Governor-General of India
- The Resident at Aden
- The Political Resident A senior ranking political representative (equivalent to a Consul General) from the diplomatic corps of the Government of India or one of its subordinate provincial governments, in charge of a Political Residency. in the Persian Gulf The historical term used to describe the body of water between the Arabian Peninsula and Iran.
- The Political Agent A mid-ranking political representative (equivalent to a Consul) from the diplomatic corps of the Government of India or one of its subordinate provincial governments, in charge of a Political Agency. in Muscat
- The Political Agent A mid-ranking political representative (equivalent to a Consul) from the diplomatic corps of the Government of India or one of its subordinate provincial governments, in charge of a Political Agency. in Zanzibar.
- Extent and format
- 1 volume (395 folios)
- Arrangement
The abstracts are arranged in roughly chronological order. A detailed index of subjects, places and people mentioned in the correspondence is included on folios 384-393.
- Physical characteristics
Foliation: the foliation sequence (used for referencing) commences at the first folio with 1, and terminates at the last folio with 395; these numbers are written in pencil, are circled, and are located in the top right corner of the recto The front of a sheet of paper or leaf, often abbreviated to 'r'. side of each folio. The foliation sequence does not include the front and back covers.
Pagination: the file also contains an original printed pagination sequence.
- Written in
- English in Latin script View the complete information for this record
Use and share this item
- Share this item
'ABSTRACT OF LETTERS FROM INDIA 1870' [52v] (111/798), British Library: India Office Records and Private Papers, IOR/L/PS/20/CA10, in Qatar Digital Library <https://www.qdl.qa/archive/81055/vdc_100135113391.0x000070> [accessed 24 July 2026]
https://www.qdl.qa/en/archive/81055/vdc_100135113391.0x000070
Copy and paste the code below into your web page where you would like to embed the image.
<meta charset="utf-8"><a href="https://www.qdl.qa/en/archive/81055/vdc_100135113391.0x000070">'ABSTRACT OF LETTERS FROM INDIA 1870' [‎52v] (111/798)</a> <a href="https://www.qdl.qa/en/archive/81055/vdc_100135113391.0x000070"> <img src="https://iiif.qdl.qa/iiif/images/81055/vdc_100000000912.0x0000db/IOR_L_PS_20_CA10_0111.jp2/full/!280,240/0/default.jpg" alt="" /> </a>
This record has a IIIF manifest available as follows. If you have a compatible viewer you can drag the icon to load it.https://www.qdl.qa/en/iiif/81055/vdc_100000000912.0x0000db/manifestOpen in Universal viewerOpen in Mirador viewerMore options for embedding images
Copyright: How to use this content
- Reference
- IOR/L/PS/20/CA10
- Title
- 'ABSTRACT OF LETTERS FROM INDIA 1870'
- Pages
- front, back, spine, edge, head, tail, front-i, 1r:116v, 119r:395v, back-i
- Author
- East India Company, the Board of Control, the India Office, or other British Government Department
- Usage terms
- Open Government Licence